Terms of Service.

By accessing or using the CLIQBUILT website at cliqbuilt.com (the “Site”), requesting a quote, submitting a lead form, booking a consultation, or entering into a project agreement with CLIQBUILT (“Company,” “we,” “us,” or “our”), you (“Customer,” “you,” or “your”) agree to be bound by these Terms of Service (“Terms”). If you do not agree to these Terms, do not use the Site or our services. These Terms apply to all visitors, users, and customers of CLIQBUILT.

CLIQBUILT is a licensed home improvement contractor operating in the State of New Jersey. We hold a New Jersey Home Improvement Contractor (HIC) license and are bonded and insured. We specialize in roofing replacement, window replacement, bathroom remodeling, flooring installation, and exterior door replacement for residential properties in Central and South New Jersey.

Our principal place of business is in New Jersey. All services are performed by CLIQBUILT W-2 employees or properly licensed and insured subcontractors engaged by CLIQBUILT.

CLIQBUILT provides residential home improvement services including but not limited to: roofing tear-off and replacement, window replacement, bathroom remodeling and conversions, flooring installation, and exterior door replacement. All services are subject to:

• Geographic availability within our service area
• A completed project assessment (virtual or in-home)
• Execution of a written project agreement signed by both parties
• Receipt of required deposit per the project agreement
• Permit issuance where required by local jurisdiction

CLIQBUILT reserves the right to decline any project request at its sole discretion, including but not limited to projects outside our service area, projects that present safety hazards, or projects for which we cannot obtain the necessary materials or permits.

Published starting prices on our website represent estimated minimum costs for standard scopes under typical conditions. They are provided for informational purposes and are not binding offers. Final project pricing is determined after a thorough assessment of your specific property, scope of work, and materials selection, and is confirmed in a written project agreement before any work begins.

CLIQBUILT may revise a quoted price if:

• Site conditions materially differ from what was represented at the time of estimate
• Hidden or latent defects are discovered during demolition or inspection (e.g., rotted decking, structural damage)
• Material costs change materially between quote and project start due to supplier price increases
• Customer-initiated scope changes are requested after the agreement is signed

Any price revision will be presented to the Customer for approval before additional work proceeds. CLIQBUILT will not perform work beyond the original agreed scope without a signed written change order.

Consistent with the requirements of the New Jersey Home Improvement Practices Regulations (N.J.A.C. 13:45A-16), all home improvement contracts valued at $500 or more must be in writing. No work will commence until a written project agreement has been signed by both the Customer and an authorized representative of CLIQBUILT. The project agreement will specify:

• Full scope of work and materials to be used
• Project pricing and payment schedule
• Estimated start and completion dates
• Warranty terms
• Permit responsibilities
• Change order procedures
• Cancellation and refund terms

These Terms of Service are incorporated by reference into all project agreements. In the event of a conflict between these Terms and a specific project agreement, the project agreement controls.

In accordance with New Jersey law and the Federal Trade Commission’s Cooling-Off Rule, for home improvement contracts solicited at or negotiated from a location other than our permanent place of business (including your home or a temporary event location), you have the right to cancel the contract within three (3) business days of signing without penalty or obligation.

To exercise this right, you must notify CLIQBUILT in writing before midnight of the third business day following the date of the contract. Written notice may be sent by:

• Email to hello@cliqbuilt.com with the subject line “Contract Cancellation”
• Certified mail to CLIQBUILT’s address shown on your project agreement

For contracts signed remotely (online, by email, or via electronic signature platforms), cancellation notice must be received within three (3) business days of the date you signed. If you cancel within this period, any deposit paid will be refunded within 10 business days of receipt of your cancellation notice.

Payment terms are specified in each project agreement. Standard payment structure is as follows, though terms may vary by project size and type:

• Deposit: Due upon signing the project agreement (amount specified in agreement)
• Progress payment(s): Due upon reaching specified project milestones, if applicable
• Final payment: Due upon substantial completion of work

Accepted payment methods include check, ACH bank transfer, and major credit cards (processing fees may apply for credit card payments). We do not accept cash payments for project agreements. All invoices are due within the timeframe specified in the project agreement. Late payments may incur interest at the rate of 1.5% per month (18% per annum) on the unpaid balance, or the maximum rate permitted by New Jersey law, whichever is less.

CLIQBUILT reserves the right to suspend work on any project where payment obligations are not met in accordance with the project agreement.

Any changes to the scope of work, materials, or timeline after a project agreement is signed must be documented in a written change order signed by both parties before the change is implemented. Verbal agreements to change the scope of work are not binding. Change orders may affect project pricing, timeline, and warranty terms. CLIQBUILT will not perform work beyond the originally agreed scope without a signed change order, and you agree not to request work beyond the agreed scope without following this process.

Many home improvement projects require permits from local New Jersey municipalities. CLIQBUILT will obtain all required permits for your project unless otherwise specified in the project agreement. Permit costs are the responsibility of the Customer and will be included in the project agreement pricing.

The Customer agrees to: (a) provide CLIQBUILT reasonable access to the property for the purpose of permit applications and inspections; (b) not permit other contractors or persons to perform work on the project scope during the CLIQBUILT project without written consent; and (c) cooperate with all required municipal inspections.

Project timelines may be affected by permit processing times and inspection scheduling, which are outside CLIQBUILT’s control. Delays attributable to permitting and inspections do not constitute a breach of contract.

Workmanship Warranty. CLIQBUILT provides a workmanship warranty on all completed projects. The duration and specific terms of the workmanship warranty are specified in your project agreement. The workmanship warranty covers defects in installation technique and craftsmanship. It does not cover damage caused by: acts of nature, improper maintenance by the homeowner, damage caused by third parties, or pre-existing structural deficiencies not disclosed at the time of the project.

Manufacturer Warranties. Most products installed by CLIQBUILT carry manufacturer warranties separate from our workmanship warranty. The terms of manufacturer warranties are controlled by the respective manufacturers and may require product registration by the Customer. CLIQBUILT will assist Customers in registering products and understanding manufacturer warranty terms where applicable.

Warranty Claims. To make a warranty claim, contact CLIQBUILT in writing at hello@cliqbuilt.com. CLIQBUILT will respond to warranty claims within 5 business days and, where a valid claim is confirmed, will schedule remediation work within a reasonable timeframe.

Exclusions. Warranties are void if: (a) the Customer or an unauthorized party performs alterations or repairs to the warranted work; (b) the Customer fails to maintain the installation per manufacturer guidelines; or (c) payment obligations under the project agreement are not fulfilled in full.

To enable CLIQBUILT to perform work effectively and safely, the Customer agrees to:

• Provide safe, unobstructed access to the work area during scheduled project hours
• Remove personal property, furniture, and valuables from the work area prior to project start
• Disclose all known material conditions of the property that may affect the project (e.g., previous water damage, structural concerns, hazardous materials)
• Ensure that pets and children are kept away from the work area during project hours
• Ensure a responsible adult (18+) is present or reachable during the project
• Not interfere with or direct the work of CLIQBUILT crews during project execution

CLIQBUILT is not responsible for damage to personal property that the Customer failed to remove from the work area, or for delays caused by the Customer’s failure to fulfill these responsibilities.

If a Customer cancels a project agreement after the three-day cancellation period has passed, the following cancellation fees apply (unless otherwise specified in the project agreement):

• More than 14 days before scheduled project start: Deposit forfeited; no additional charges
• 8–14 days before scheduled project start: Deposit forfeited plus up to 15% of project value for materials ordered
• 7 days or fewer before scheduled project start: Deposit forfeited plus actual costs incurred (materials ordered, permits obtained, crew scheduling costs)
• After project has commenced: Customer is responsible for all work completed to date plus reasonable demobilization costs

Cancellation fees reflect CLIQBUILT’s actual costs and lost scheduling opportunity and are not penalties.

All content on the Site — including text, photographs, videos, graphics, logos, and software — is the property of CLIQBUILT or its content licensors and is protected by applicable copyright, trademark, and intellectual property laws. You may not reproduce, distribute, modify, or create derivative works from any Site content without prior written permission from CLIQBUILT. Limited, non-exclusive permission is granted to view and print content from the Site solely for your personal, non-commercial use in evaluating CLIQBUILT’s services.

You agree to use the Site only for lawful purposes. You agree not to:

• Use the Site in any way that violates applicable federal, state, or local laws
• Submit false or misleading information in any form or quote request
• Attempt to gain unauthorized access to any portion of the Site or its systems
• Use automated tools to scrape, crawl, or harvest data from the Site without written permission
• Upload or transmit any malicious code, viruses, or harmful content
• Impersonate any person or entity or misrepresent your affiliation with any person or entity
• Use the Site to transmit unsolicited commercial communications

THE SITE AND ITS CONTENT ARE PROVIDED “AS IS” AND “AS AVAILABLE” WITHOUT WARRANTY OF ANY KIND, EXPRESS OR IMPLIED, INCLUDING BUT NOT LIMITED TO WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, NON-INFRINGEMENT, OR ACCURACY. CLIQBUILT DOES NOT WARRANT THAT THE SITE WILL BE UNINTERRUPTED, ERROR-FREE, OR FREE OF VIRUSES OR OTHER HARMFUL COMPONENTS. THIS DISCLAIMER APPLIES TO THE WEBSITE AND SITE CONTENT ONLY. WARRANTIES APPLICABLE TO PHYSICAL SERVICES AND INSTALLATIONS ARE SET FORTH IN THE APPLICABLE PROJECT AGREEMENT.

TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, CLIQBUILT’S TOTAL LIABILITY TO YOU FOR ANY CLAIM ARISING OUT OF OR RELATING TO THESE TERMS OR OUR SERVICES — WHETHER IN CONTRACT, TORT, STRICT LIABILITY, OR OTHERWISE — IS LIMITED TO THE GREATER OF: (A) THE TOTAL AMOUNT PAID BY YOU TO CLIQBUILT FOR THE SPECIFIC PROJECT GIVING RISE TO THE CLAIM IN THE TWELVE (12) MONTHS PRECEDING THE CLAIM, OR (B) $500.

IN NO EVENT WILL CLIQBUILT BE LIABLE FOR ANY INDIRECT, INCIDENTAL, SPECIAL, CONSEQUENTIAL, EXEMPLARY, OR PUNITIVE DAMAGES, INCLUDING BUT NOT LIMITED TO LOSS OF PROFITS, LOSS OF REVENUE, LOSS OF DATA, LOSS OF GOODWILL, OR COST OF SUBSTITUTE SERVICES, EVEN IF CLIQBUILT HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.

Some jurisdictions do not allow limitation of liability for certain types of damages. In such jurisdictions, CLIQBUILT’s liability will be limited to the fullest extent permitted by law.

You agree to indemnify, defend, and hold harmless CLIQBUILT, its officers, employees, agents, and contractors from and against any claims, liabilities, damages, losses, costs, and expenses (including reasonable attorneys’ fees) arising out of or relating to: (a) your use of the Site or our services; (b) your violation of these Terms; (c) your violation of any third-party right, including any property or intellectual property right; (d) any misrepresentation made by you to CLIQBUILT regarding your property, project scope, or authority to authorize the project; or (e) the negligence or willful misconduct of you or any person accessing your property on your behalf.

CLIQBUILT is not liable for any delay or failure to perform resulting from causes outside our reasonable control, including but not limited to: acts of God, severe weather, natural disasters, pandemics or public health emergencies, supply chain disruptions, material shortages, labor disputes, governmental actions or permit delays, fire, flood, or other events beyond our reasonable control (“Force Majeure Events”). In the event of a Force Majeure Event, CLIQBUILT will notify you as soon as practicable and will use commercially reasonable efforts to resume performance as quickly as possible. Project timelines will be extended by the duration of the Force Majeure Event without penalty.

Informal Resolution. Before initiating any formal proceeding, you agree to contact CLIQBUILT in writing at hello@cliqbuilt.com and describe your dispute in detail. CLIQBUILT will respond within 10 business days. Both parties agree to attempt to resolve the dispute informally for at least 30 days before pursuing any other remedy.

Binding Arbitration.If informal resolution fails, any dispute arising out of or relating to these Terms or CLIQBUILT’s services (other than claims for injunctive or equitable relief to protect intellectual property) will be resolved by binding arbitration administered by JAMS under its Streamlined Arbitration Rules and Procedures, or a mutually agreed alternative arbitration provider, in New Jersey. The arbitration will be conducted in English. The arbitrator’s decision will be final and binding and may be entered as a judgment in any court of competent jurisdiction.

Class Action Waiver. You agree that any arbitration or proceeding will be conducted only on an individual basis and not in a class, consolidated, or representative action. You waive any right to participate in a class action lawsuit or class-wide arbitration against CLIQBUILT.

Exception. Either party may seek emergency injunctive or other equitable relief from a court of competent jurisdiction to prevent irreparable harm while arbitration is pending.

These Terms are governed by and construed in accordance with the laws of the State of New Jersey, without regard to its conflict of law principles. For any matters not subject to arbitration, you consent to exclusive jurisdiction in the state and federal courts located in New Jersey, and waive any objection to venue or jurisdiction in such courts.

The Site may contain links to third-party websites or resources. These links are provided for convenience only. CLIQBUILT has no control over the content, privacy policies, or practices of third-party sites and is not responsible for any content, products, or services available on those sites. Your use of third-party sites is at your own risk and subject to the terms and policies of those sites.

If any provision of these Terms is found to be unlawful, void, or unenforceable, that provision will be deemed severable from these Terms and will not affect the validity and enforceability of any remaining provisions. The remaining provisions will continue in full force and effect.

These Terms, together with our Privacy Policy and any applicable project agreement, constitute the entire agreement between you and CLIQBUILT regarding the subject matter herein and supersede all prior or contemporaneous communications, representations, or agreements, whether written or oral, relating to that subject matter. No modification of these Terms is binding unless made in writing and signed by an authorized representative of CLIQBUILT.

CLIQBUILT reserves the right to update or modify these Terms at any time. When we make material changes, we will update the “Last updated” date at the top of this page. We may also provide additional notice for material changes, such as an email notification or a banner on the Site. Your continued use of the Site or our services after any changes constitutes your acceptance of the updated Terms. We encourage you to review these Terms periodically.

If you have questions about these Terms of Service, please contact us:

• CLIQBUILT
• Email: hello@cliqbuilt.com
• Phone: (000) 000-0000
• Website: cliqbuilt.com

These Terms of Service are provided for informational purposes and do not constitute legal advice. CLIQBUILT recommends that customers consult their own legal counsel for advice on specific legal matters.